Published
Planung 3 BÜ - Striessen, Priestewitz, Baßlitz Planungsleistung OPL VA - Lph 1-2 über.; Lph 3-4,6-7
Notice number: 00572888-2026
KEY INFORMATION
- Submission deadline
- • Sep 25, 2026
- Location
- 🇩🇪 Germany
- Contracting authority
- DB InfraGO AG – Geschäftsbereich Fahrweg (Bukr 16)
- Accepted Languages
- German
- Tender type
- Services
- Contract Value
- Published date
- Aug 19, 2026
TENDER DESCRIPTION
This tender seeks comprehensive planning services for three railway bridge structures in Striessen, Priestewitz, and Baßlitz, encompassing road and level crossing surfacing (new construction and demolition), and superstructure work. The project mandates extensive Building Information Modeling (BIM) throughout the lifecycle, including model-based planning, construction scheduling, cost estimation, and life cycle cost (LCC) determination, utilizing CAD software, Siemens SIMIS C, and the iTWO/iTWO 5D system for procurement documentation. The contract is scheduled to commence on December 22, 2026, and conclude on July 31, 2030, with critical Quality Gate milestones, monthly progress presentations, and a 12-week client review period integrated into the schedule. Bidders must demonstrate financial stability, including no pending insolvency or liquidation, compliance with tax and social security obligations, and for individual bidders, a declaration of self-employment and assurance of diversified income sources.
TENDER BRIEF
The contract is scheduled to begin on December 22, 2026, and conclude on July 31, 2030. This results in a total duration of approximately 3 years and 7 months.
Key milestones and phases include:
- The contract's service periods are subdivided into specific service phases and trades, which are accounted for in the schedule.
- A detailed project and work plan must be submitted by the contractor within two weeks of the contract award. This plan, along with the current status, needs to be presented to the client monthly.
- Quality Gate (QG) milestones are integral to the contract:
- QG 1 marks the commencement of services.
- QG 2 takes place during the service delivery phase, ideally at the midpoint of the contract. For contracts exceeding one year, multiple QG 2s can be scheduled, with up to two additional QG 2s per year. A QG 2 is also mandated if the responsible project manager changes.
- QG 3 occurs at the completion of services, following the contractual acceptance of the overall performance and before the submission of the final invoice.
- All QG AN dates must be established as milestones within 30 calendar days following the contract award.
- The schedule must incorporate quality assurance periods, such as internal quality control and interim checks.
- Review periods for the client, spanning 12 weeks, as well as subsequent times for corrections, revisions, and official approvals, are to be included in the timeline.
- Buffer times and the critical path for meeting contractual obligations must be identified in the project schedule.
Sources
- 10.1_Angebotserklärung_10.08.pdf — “Übertragung dieser Leistung hat er nicht, und zwar auch dann nicht, wenn die Planung fortgesetzt bzw. die Baumaßnahme durchgeführt wird. Aus der stufenweisen Übertragung kann der AN keinen Anspruch auf Erhöhung seines Ho…”
- 2Unterlagen\Weitere Dokumente\Zuschlagsmatrix.xlsx — “Punkte ,Begründung der Punktbewertung,Erreiche Punktzahl ,2.2.0,"Anforderung sind nicht erfüllt, keine Daten abgegeben",0,,,0,,,0,,,0,,,0,,,0,, ,2.2.1,Die gemäß Arch.-/Ing.-Vertrag vereinbarten Vertragsfristen und Vertra…”
- 301.0 Projektbeschreibung u Vorbem_Planung_BIM (1).pdf — “Vertrag Nr. 26FEI88112 (BIM) 2 2.1 2.2 Vorbemerkungen Besprechungen, Termine, Niederschriften Alle erforderlichen Kosten einschließlich Nebenkosten für Besprechungen beim Auftraggeber (AG) und bei Dritten zur vollständig…”
- 413.0_Quality Gates.pdf — “einer QG-Sitzung auf Basis eines vorgegebenen, von vornherein bekannten Fragenkataloges (Checkliste). Die Durchführung einer Quality Gate Sitzung setzt ein übereinstimmendes Verständnis der beteiligten Partner für das ge…”
- BIM model
- CAD software
- Siemens SIMIS C
Sources
- 101.3_BIM_Technische_Ausrüstung_EVU-Anschluss_(ZAS).pdf — “und zu beurteilen. Es werden erwartet: - Überschlägige Dimensionierung der Versorgungsmedien aller Nutzungsbereiche differenziert nach Vermarktungsbereich und Verkehrsstation einschl. aller abhängigen und mit zu versorge…”
- 2Unterlagen\Weitere Dokumente\Teilnahmeantrag_10.08 (2).docx — “Unternehmen zu erbringen. Die technische Ausstattung muss für die Erfüllung der ausgeschriebenen Leistungen geeignet sein. Die Nachweisführung erfolgt als Eigenerklärung mit dem Formular „Technische Ausstattung des Bewer…”
- 36363 BÜ km 84,6 BASt V1_2.pdf — “Asphalt Mittig: Innenplatten Bahnrechts: Asphalt Oberbau Gleis 23: | B90 Schwellen/teilweise Weichenschwellen, W-Befestigung, S 54 BÜ-Befestigung System Bodan: | Bahnlinks: Asphalt Mittig: Innenplatten Bahnrechts: Innenp…”
- 46363 BÜ km 83,6 T_016085977_BAst_1_2.pdf — “Siemens SIMIS C (siehe Einschaltstreckenberechnung) ☐ Nein TK ☑ Ja: Fernsprecher am BÜ ist außer Betrieb ☐ Nein ☑ OLA Ja: Die Strecke 6363 ist im betreffenden Abschnitt mit 15kV, 16,7 Hz elektrifiziert. Im I. und II. Qua…”
Login to view all answers and insights
Unlock tender brief for freeTENDER DOCUMENTS
DIRECTORY • 33 FILES
- 3.1.3_Technische_Ausrüstung_EVU-Anschluss_(ZAS).pdf168 KBPDF
- 18_AIA der DB InfraGO AG.pdf971 KBPDF
- 6363 BÜ km 83,6 T_016085977_BAst_1_2.pdf751 KBPDF
and 26 other documents
Login to view and download all tender documents
Unlock documents for freeASK AI ABOUT THIS TENDER
Can a foreign company apply?
Yes, foreign companies can apply as long as they meet all the requirements set out in the procurement documents.
Login to ask more questions.
Unlock AI tender chat for freeUnlock your tender workflow
Run your first search, evaluate the results, save a daily monitor and start building a pipeline of tenders worth pursuing.